1. Definitions: The definitions of terms used to interpret this Purchase Order ("Order") and the rights of the parties to this Order ("Parties") are construed under and governed by the substantive laws of the State in which this Order is signed, without regard to conflict of law provisions. "Buyer" means the entity indicated on the front of this Order. "Seller" means the person, firm or corporation to which this Order is addressed. Whenever Buyer is not the ultimate consumer of Products or Services, all rights, benefits, warranties, indemnities and remedies conferred upon Buyer by this Order accrue to and are intended by the Parties for the express benefit of such client or user of the Products or Services as intended beneficiaries of this Order. "Goods" means the items ordered by this Order that are provided by Seller to Buyer. The term "Goods" also encompasses associated articles, materials, drawings, data, information and other property, together. "Services" means, individually or collectively, any of the services set forth in this Order.Notwithstanding anything herein to the contrary, if a written contract signed by any Buyer and Seller is in existence covering the sale of the Goods and Services covered hereby (an “Existing Agreement”) in which the parties have expressly agreed such contract will override these Terms in the event of a conflict, thereto terms and conditions of such contract will prevail with respect to such parties to the extent they are inconsistent with these Terms.
(a) Any Existing Agreement, any purchase order which from time to time may be issued by Buyer (each, a “Purchase Order”), and these Terms (collectively, this “Agreement”) comprise the entire agreement between the parties, and supersede all prior or contemporaneous understandings, agreements, negotiations, representations and warranties and communications, both written and oral. In the event of any conflict between any provisions of such documents, the provisions of such documents will control in the following priority order: (i) the terms of the Existing Agreement; then (ii) these Terms; and then (iii) the Purchase Order.
(b) These Terms prevail over any of Seller’s general terms and conditions of sale and Seller’s other commercial documents (including without limitation any proposal, offer to sell, quotation, order confirmation, acknowledgment, bill of lading or invoice) regardless whether or when Seller has submitted such documents. Reference in any Purchase Order to any such commercial document will in no way constitute a modification of any of the terms of this Agreement. Any terms contained in any commercial document of Seller or proposed at any time by Seller in any manner, written or oral, which add to, vary from or conflict with the terms and conditions in this Agreement are deemed to be material alterations, and notwithstanding any acceptance of Goods or Services by Buyer or other course of conduct, such terms will be deemed to be objected to and rejected by Buyer without need of further notice thereof and will be of no effect or in any circumstance binding upon Buyer unless expressly accepted by Buyer in writing. Written acceptance or rejection by Buyer of any particular additional term or condition will not constitute an acceptance by Buyer of any other additional term or condition.
(c) The shipment of any Goods and/or the performance of any Services (or the delivery of any deliverable arising therefrom) will constitute acceptance of any Purchase
Order in connection therewith and will constitute acceptance by Seller of the terms and conditions contained in this Agreement. Buyer may withdraw any Purchase Order at any time.
2. Delivery of Goods and Performance of Services.
(a) Seller must deliver the Goods in the quantities and on the date(s) specified in any Purchase Order or as otherwise directed in writing by Buyer (the “Delivery Date”). If Seller fails to deliver the Goods in full on the Delivery Date, Buyer may terminate this Agreement or any Purchase Order immediately by providing written notice to Seller and Seller will indemnify, defend and hold harmless Buyer and the Indemnitees (as defined below) against any losses, claims, damages and reasonable costs and expenses directly attributable to Seller’s failure to deliver the Goods on the Delivery Date. Buyer has the right to return any Goods delivered prior to the Delivery Date at Seller’s expense and Seller must redeliver such Goods on the Delivery Date.
(b) Seller will deliver all Goods to the address specified in the applicable Purchase Order or as otherwise directed in writing by Buyer (the “Delivery Point”) during Buyer’s normal business hours or as otherwise instructed by Buyer. Seller will pack all goods for shipment according to Buyer’s instructions or, if there are no instructions, in a manner sufficient to ensure that the Goods are delivered in undamaged condition. Seller must provide Buyer prior written notice if Seller requires Buyer to return any packaging material. Any return of such packaging material will be made at Seller’s risk of loss and expense.
(c) Seller will provide the Services to Buyer as described in the applicable Purchase Order or as otherwise directed in writing by Buyer, and in accordance with these Terms.
(d) Seller acknowledges that time is of the essence with respect to Seller’s obligations hereunder and the timely delivery of the Goods and Services, including without limitation all performance dates, timetables, project milestones and other requirements in this Agreement.
(e) These Terms apply to any repaired or replacement Goods.
(a) Buyer is not obligated to purchase any quantity of Goods and/or Services except for such quantity(ies) as may be specified either: (i) in a Purchase Order; or (ii) on a separate written release issued by Buyer pursuant to a Purchase Order.
(b) If Seller delivers more or less than the quantity of Goods ordered and/or in advance of schedule, Buyer may reject all or any excess Goods. Any such rejected
Goods will be returned to Seller at Seller’s sole risk and expense, including without limitation any cost incurred by Buyer related to storage and handling of such Goods.
(c) If Buyer does not reject the Goods and instead accepts the delivery of Goods at the increased or reduced quantity, the Price (as defined below) for the Goods will be adjusted on a pro-rata basis.
(d) Unless otherwise agreed to in writing by Buyer, Seller will not make material commitments or production arrangements in excess of the quantities specified in a Purchase Order or release and/or in advance of the time necessary to meet Buyer’s delivery schedule. Should Seller enter into such commitments or engage in such production, any resulting exposure will be for Seller’s account.
4. Shipping Terms. Unless otherwise stated on a Purchase Order, all Goods will be delivered DDP (Incoterms® 2010) Delivery Location. Buyer may specify contract of carriage in all cases. Failure of Seller to comply with any such Buyer specification will cause all resulting transportation charges to be for the account of Seller and give rise to any other remedies available at law or equity. Seller will give written notice of shipment to Buyer when the Goods are delivered to a carrier for transportation. Seller will provide Buyer all shipping documents, including without limitation the commercial invoice, packing list and any other documents necessary to release the Goods to Buyer within two business days after Seller delivers the Goods to the transportation carrier. The Purchase Order number must appear on all shipping documents, shipping labels, invoices, correspondence and any other documents pertaining to the Purchase Order.
5. Title and Risk of Loss. Title passes to Buyer upon the earlier of delivery of the Goods to the Delivery Location or payment of the Price for such Goods. Seller will bear all risk of loss or damage to the Goods until delivery of the Goods to the Delivery Point.
6. Inspection and Rejection of Nonconforming Goods.
(a) Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods. Buyer may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective.
(b) If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, in addition to any other rights and remedies it may have by law, contract or at equity, and in addition to seeking recovery of any and all damages and costs emanating therefrom, at its option and sole discretion and at Seller’s expense, to: (i) terminate or rescind this Agreement and/or any Purchase Order in whole or in part without liability; (ii) accept the Goods at a reasonably reduced price; (iii) reject and return the Goods; (iv) or require immediate repair or replacement of the rejected Goods.
(c) If Buyer requires replacement of the Goods, Seller will, at its expense, promptly replace the nonconforming or defective Goods and pay for all related expenses, including without limitation transportation charges for the return of the defective Goods and the delivery of replacement Goods. For any repairs or replacements, Seller, at its sole cost and expense, will perform any tests requested by Buyer to verify conformance to the applicable Purchase Order. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Agreement for cause pursuant to Section 17(a).
(d) Any inspection or other action by Buyer under this Section will not reduce or otherwise affect Seller’s obligations under the Agreement, and Buyer will have the right to conduct further inspections after Seller has carried out its remedial actions.
(a) The price of the Goods and Services will be the price stated in the Existing Agreement (the “Price”). If no price is included in the Existing Agreement, or if there is no Existing Agreement, the Price will be the price set out in the applicable Purchase Order. If no price is included in the applicable Purchase Order, the Price will be the price set out in Seller’s published price list in force as of the date of the Purchase Order.
(b) Unless otherwise specified in the Purchase Order, the Price includes all packaging, transportation costs to the Delivery Point, insurance, customs duties and fees and applicable taxes, including without limitation all sales, use or excise taxes. If Seller is obligated by law to charge any value added and/or similar tax to Buyer, Seller will ensure that if such value added and/or similar tax is applicable, that it is invoiced to Buyer in accordance with applicable rules so as to allow Buyer to reclaim such value added and/or similar tax from the appropriate government authority.
(c) No increase in the Price will be effective, whether due to increased material, labor or transportation costs or otherwise, without the prior written consent of Buyer, which may be withheld in Buyer’s sole discretion.
8. Payment Terms.
(a) Seller will issue an invoice to Buyer on or any time after the completion of delivery and only in accordance with these Terms.
(b) Buyer will pay all properly invoiced amounts due to Seller within 60 days after Buyer’s receipt of such invoice, except for any amounts disputed by Buyer in good faith. In the event of a payment dispute, Buyer will deliver a written statement to Seller listing all disputed items and providing a reasonably detailed description of each disputed item. The parties will seek to resolve all such disputes expeditiously and in good faith.
Seller will continue performing its obligations under this Agreement notwithstanding any such dispute.
(c) Without prejudice to any other right or remedy it may have, Buyer reserves the right to set off at any time any amount owing to Buyer by Seller against any amount payable by Buyer to Seller.
(d) All payments hereunder must be in US dollars and made by check, wire transfer, credit card or ACH.
9. Seller’s Obligations Regarding Services.
(a) Seller will, before the date on which the Services are to start, obtain, and at all times during the term of this Agreement, maintain, all necessary licenses and consents and comply with all laws and regulations applicable to the provision of the Services.
(b) Seller will at all times comply with all rules, regulations and policies of Buyer, including without limitation security procedures concerning systems and data and remote access thereto, building security procedures, including without limitation the restriction of access by Buyer to certain areas of its premises or systems for security reasons, and general health and safety practices and procedures.
(c) Seller will obtain Buyer’s written consent, which may be withheld in Buyer’s sole discretion, prior to entering into agreements with or otherwise engaging any person or entity, including all subcontractors and affiliates of Seller, other than Seller’s employees, to provide any Services to Buyer (each such approved subcontractor or other third party, a “Permitted Subcontractor”). Buyer’s approval will not relieve Seller of its obligations under the Agreement, and Seller will remain fully responsible for the performance of each such Permitted Subcontractor and its employees and for their compliance with all of the terms and conditions of this Agreement as if they were Seller’s own employees.
(d) Seller will require each Permitted Subcontractor to be bound in writing by the confidentiality provisions of this Agreement, and, upon Buyer’s written request, to enter into a non-disclosure or intellectual property assignment or license agreement in a form that is reasonably satisfactory to Buyer;
(e) Seller will ensure that all persons, whether employees, agents, subcontractors or anyone acting for or on behalf of Seller, are properly licensed, certified or accredited as required by applicable laws and regulations and are suitably skilled, experienced and qualified to perform the Services.
(f) Seller will ensure that all of its equipment used in the provision of the Services is in good working order and suitable for the purposes for which it is used, and conforms to all relevant legal standards and standards specified by Buyer.
(g) Seller will keep and maintain any Buyer equipment in its possession in good working order and will not dispose of or use such equipment other than in accordance with Buyer’s written instructions or authorization.
10. Change Orders. Buyer may at any time, by written instructions and/or drawings issued to Seller (each a “Change Order”), order changes to the Services. Seller will within five days of receipt of a Change Order submit to Buyer a firm cost proposal for the Change Order. If Buyer does not accept such cost proposal, Buyer may terminate this Agreement without any liability. If Buyer accepts such cost proposal, Seller will proceed with the changed services subject to the cost proposal and the terms and conditions of this Agreement.
(a) Seller warrants to Buyer that for a period of 24 months from the Delivery Date, all Goods will:
(i) be free from any defects in workmanship, material and design;
(ii) conform to applicable specifications, drawings, designs, samples and other requirements specified by Buyer or otherwise mutually agreed upon;
(iii) be fit for their intended purpose and operate as intended;
(iv) be merchantable;
(v) be free and clear of all liens, security interests or other encumbrances; and
(vi) not infringe or misappropriate any third party’s patent, trademark, copyright, trade secret or other intellectual property rights.
These warranties survive any delivery, inspection, acceptance or payment of or for the Goods by Buyer.
(b) Seller warrants to Buyer that Seller will perform the Services using personnel of required skill, experience and qualifications and in a professional and workmanlike manner in accordance with generally recognized industry standards for similar services and will devote adequate resources to meet its obligations under this Agreement.
(c) The warranties set forth in this Section 11 are cumulative and in addition to any other warranty provided by law or equity. Any applicable statute of limitations runs from the date of Buyer’s discovery of the noncompliance of the Goods or Services with the foregoing warranties. If Buyer gives Seller notice of noncompliance pursuant to
this Section, Seller will, at its own cost and expense, promptly: (i) replace or repair the defective or nonconforming Goods and pay for all related expenses, including without limitation transportation charges for the return of the defective or nonconforming Goods to Seller and the delivery of repaired or replacement Goods to Buyer, and, if applicable,
(ii) re-perform the applicable Services.
12. Safety and Security:
(a) Seller's agents, employees, and representatives, while assigned to work on behalf of the Buyer, shall comply with all applicable Buyer rules, regulations, policies, practices, and directives governing conduct, environmental, safety, and security, including in connection with access to any Buyer facility, computer, or electronic data storage system.
(b) Seller shall be solely responsible for ensuring that the agents, employees and representatives who are assigned to perform work on its behalf for Buyer, are properly trained and capable of performing their work in compliance with all federal, State and local environmental and safety requirements, including, but not limited to those requirements under OSHA and U.S.EPA and their State and local counterparts. In addition to ensuring proper training, Seller shall also provide the agents, employees and representatives with all appropriate personal protective and safety equipment necessary to perform the tasks safely and in compliance with all legal requirements.
(c) Seller represents and warrants that all employees, agents, or representatives assigned to work on behalf of Buyer, have had a pre-employment background check and drug screening, which has been updated within the last thirty six (36) months. The drug screening shall include, at a minimum, a standard 10 panel, plus ecstasy. The background check shall include, at a minimum; a seven (7) year history for statewide and county criminal, basic nationwide scan, social security verification, employment verification, education verification, credit check for roles that require access to secure financial data, and motor vehicle report (if the employee, agent or representative will be driving a Buyer vehicle, or a non-Buyer vehicle for Buyer business). Buyer must pre-approve any deviation from the above requirements prior to the start of any work assignment. Buyer also reserves the right to require an update of part or all of the background check for employees, agents, or representatives assigned to work on its behalf. If the background check indicates any criminal conviction(s), a negative score or information of any kind (such as a poor score on a credit check, unconfirmed social security number or education credentials, or a Motor Vehicle violation), or a positive result from the drug screening, this must be reported to Buyer prior to Seller’s employee, agent, or representative being assigned to work on behalf of Buyer. In addition, if Seller becomes aware of an active employee, agent, or representative already working for Buyer being convicted of a crime or testing positive for drugs since the drug screen or background check was completed; Buyer must be notified in writing in accordance with the Notice section of this Agreement. Any notice or report required by this Section must also be sent to Buyers Risk and Compliance leads. Buyer reserves the right to review the background checks at any time.
(d) Seller represents and warrants that it is in compliance with the Department of Justice From I-9 requirements governing proof of authorization to work in the United States.
(e) Buyer reserves the right to refuse anyone access to its premises, or remove anyone from its premises for any reason, in its sole discretion.
(f) Seller agrees that all employees, contractors or agents assigned by Seller to fulfill this Agreement shall read and obey all applicable work rules, polices and regulations established by Buyer regarding the conduct of its own employees, including, but not limited to Buyer’s Code of Business Conduct & Ethics, and Buyer’s Environmental, Health and Safety Manual.
(g) Buyer shall have the right to modify its work rules, policies and regulations, or promulgate additional rules, policies and regulations, and Seller and its employees, contractors and agents shall comply with such modified or additional rules, policies and regulations immediately following Seller’s receipt of written notice thereof.
13. Recall. If any governmental authority seizes or orders recall of any of the Goods or if Seller deems it necessary to recall any Goods for any reason, Seller will reimburse Buyer for all direct and consequential damages incurred by Buyer in connection with such seizure or recall and, at Buyer’s option, either: (a) replace, at no cost to Buyer, the seized or recalled Goods with an equal quantity of complying Goods; or (b) refund the purchase price paid by Buyer for such Goods.
14. General Indemnification. Seller will defend, indemnify and hold harmless Buyer and its subsidiaries and parent companies and their respective affiliates, successors and assigns and all of their respective directors, managers, officers, members, partners, shareholders, owners and employees, and Buyer’s customers, (collectively, “Indemnitees”) against any and all loss, injury, death, damage, liability, claim, deficiency, action, judgment, interest, award, penalty, fine, cost or expense, including without limitation reasonable attorney and professional fees and costs, and the cost of enforcing any right to indemnification hereunder and the cost of pursuing any insurance providers (collectively, “Losses”) arising out of or occurring in connection with the Goods and Services or Seller’s negligence, willful misconduct or breach of any of the Terms. Seller will not enter into any settlement without Buyer’s prior written consent.
15. Intellectual Property Indemnification. Seller will, at its expense, defend, indemnify and hold harmless Buyer and any Indemnitee against any and all Losses arising out of or in connection with any claim that Buyer’s or Indemnitee’s use or possession of the Goods or use of the Services infringes or misappropriates the patent, trademark, copyright, trade secret or other intellectual property right of any third party. In no event will Seller enter into any settlement without Buyer’s or Indemnitee’s prior written consent.
16. Insurance. During the term of this Agreement and for a period of ten years thereafter, Seller will, at its own expense, maintain and carry insurance in full force and effect which includes, without limitation, commercial general liability insurance (including product liability insurance) providing combined limits of liability of no less than Five Million Dollars ($5,000,000.00), with financially sound and reputable insurers. Upon Buyer’s request, Seller will provide Buyer with certificate(s) of insurance from Seller’s insurer(s) evidencing the insurance coverage specified in these Terms. The certificate(s) of insurance must name Buyer as an additional insured on all required policies. Seller will provide Buyer with 30 days’ advance written notice in the event of a cancellation or material change in Seller’s insurance policy. Except where prohibited by
law, Seller will require its insurer to waive all rights of subrogation against Seller’s insurers and Seller.
17. Compliance with Law.
a. Seller represents, warrants and covenants that Seller is in compliance with and will at all times comply with: (i) all laws and regulations applicable to the Goods and Services and otherwise in connection with the activities contemplated or provided under this Agreement, including without limitation any national, international, federal, state, provincial or local law, treaty, convention, protocol, common law, regulation, directive or ordinance and all lawful orders, including judicial orders, rules and regulations issued thereunder, including without limitation those dealing with the environment, health and safety, employment, records retention, personal data protection and the transportation or storage of hazardous materials; and (ii) good industry practices, including without limitation the exercise of that degree of skill, diligence, prudence and foresight, which can reasonably be expected from a competent seller who is engaged in the same type of service or manufacture under similar circumstances. Without limiting the foregoing, Seller will comply with all export and import laws of all countries involved in the sale of the Goods under this Agreement or any resale of the Goods by Seller. Seller assumes all responsibility for shipments of Goods requiring any government import clearance.
b. Seller will maintain in effect all the licenses, permissions, authorizations, consents and permits that it needs to carry out its obligations under this Agreement.
c. Seller has not offered or used, and Seller will not at any time offer or use, directly or indirectly, any money, property or thing of value under or in connection with this Agreement or otherwise to influence improperly or unlawfully any decision, judgment, action or inaction of any official, employee or representative of any government or agency or instrumentality thereof, or of any government owned or partially government owned entity, or any other person or entity, in connection with or relating to the subject matter of this Agreement or otherwise. Seller represents, warrants and covenants that no payment will be made nor will any transaction be entered into in connection with this Agreement or otherwise that is illegal, improper or is intended to unduly or improperly influence any third party, including without limitation by means of extortion, any kickback or bribery. If Seller breaches any term of this provision, Buyer may immediately terminate this Agreement without any liability.
d. Buyer may terminate this Agreement if any governmental authority imposes antidumping or countervailing duties, any retaliatory duties or any other penalties on Goods.
18. Termination. In addition to any remedies that may be provided under these Terms, Buyer may terminate this Agreement with immediate effect upon written notice to Seller, either before or after the acceptance of the Goods or Seller’s delivery of the Services, if Seller has not performed or complied with any of these Terms, in whole or in part.
a. If Seller becomes insolvent, files a petition for bankruptcy or commences or has commenced against it proceedings relating to bankruptcy, receivership, reorganization or assignment for the benefit of creditors, then Buyer may terminate this Agreement upon written notice to Seller.
b. If Buyer terminates the Agreement for any reason, Seller’s sole and exclusive remedy is payment for the Goods received and accepted and Services accepted by Buyer prior to the termination.
19. Limitation of Liability. Nothing in the Order will exclude or limit: (a) Seller’s liability under Sections 11, 12, 13, 14, 16 and 20; or (b) Seller’s liability for fraud, personal injury or death caused by its negligence or willful misconduct.
20. Waiver. No waiver by Buyer of any of the provisions of this Agreement will be effective unless explicitly set forth in writing and signed by Buyer. No failure to exercise, or delay in exercising, any right, remedy, power or privilege arising from this Agreement will operate, or may be construed, as a waiver thereof. No single or partial exercise of any right, remedy, power or privilege hereunder precludes any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.
21. Confidential Information. All non-public, confidential or proprietary information of Buyer or its affiliates, including without limitation specifications, samples, patterns, designs, plans, drawings, documents, data, trade secrets, business operations, customer lists, pricing, discounts or rebates, disclosed by Buyer or any of its affiliates or their respective employees, agents or representatives to Seller, whether disclosed orally or disclosed or accessed in written, electronic or other form or media, and whether or not marked, designated or otherwise identified as “confidential” in connection with this Agreement, is confidential, is disclosed solely for the purpose of performing this Agreement and may not be disclosed or copied unless authorized by Buyer in writing. Upon Buyer’s request, Seller will promptly return all documents and other materials received from Buyer and its affiliates. This Section does not apply to information that:(a) was in the public domain at the time of Seller’s receipt of such information; (b) Seller can prove by appropriate documentation was previously lawfully known to Seller at the time of disclosure; or (c) Seller can prove by appropriate documentation was rightfully obtained by Seller on a non-confidential basis from a third party. Seller: (i) acknowledges that failure to comply with this Section 20 will cause Buyer irrevocable harm and that a remedy at law for such a failure would be an inadequate remedy for Buyer; and (ii) consents to Buyer’s obtaining from a court having jurisdiction specific performance, an injunction, a restraining order or any other equitable relief in order to enforce this Section 20. The right of Buyer to obtain such equitable relief is in addition to, and not in lieu of, any other remedy (including without limitation monetary damages) to which Buyer is entitled under applicable law.
22. Records. Seller will maintain complete and accurate records relating to the provision of the Goods and Services under this Agreement, including without limitation records of the time spent and materials used by Seller, in such form as Buyer approves. During the term of this Agreement and for a period of two years thereafter, upon Buyer’s written request, Seller will allow Buyer to inspect and make copies of such records and interview Seller personnel in connection with the provision of the Goods and Services.
23. Force Majeure. Neither party will be liable to the other for any delay or failure in performing its obligations under this Agreement to the extent that such delay or failure is caused by an event or circumstance that is beyond the reasonable control of that party, without such party’s fault or negligence, and which by its nature could not have been foreseen by such party or, if it could have been foreseen, was unavoidable (“Force Majeure Event”). Force Majeure Events include acts of God or the public enemy, government restrictions, floods, fire, earthquakes, explosion, epidemic, war, invasion, hostilities, terrorist acts, riots, strike or embargoes. Seller’s economic hardship or changes in market conditions are not considered Force Majeure Events. Seller will use all diligent efforts to end the failure or delay of its performance, ensure that the effects of any Force Majeure Event are minimized and resume performance under this Agreement. If a Force Majeure Event prevents Seller from carrying out its obligations under this Agreement for a continuous period of more than 10 business days, Buyer may terminate this Agreement immediately by giving written notice to Seller without any liability.
24. Assignment. Seller will not assign, transfer, delegate or subcontract any of its rights or obligations under this Agreement without the prior written consent of Buyer. Any purported assignment or delegation in violation of this Section will be null and void. No assignment or delegation will relieve Seller of any of its obligations hereunder. Buyer may at any time assign, delegate, subcontract or transfer any or all of its rights or obligations under this Agreement without Seller’s prior written consent.
25. Relationship of the Parties. The relationship between the parties is that of independent contractors. Nothing contained in this Agreement will be construed as creating any agency, partnership, joint venture or other form of joint enterprise, employment or fiduciary relationship between the parties, and neither party will have authority to contract for or bind the other party in any manner whatsoever. No relationship of exclusivity will be construed from this Agreement.
26. Governing Law. All matters arising out of or relating to this Agreement are governed by and will be construed in accordance with the internal laws of the State of New York without giving effect to any choice or conflict of law provision or rule that would cause the application of the laws of any other jurisdiction, except that the United Nations Convention on the International Sale of Goods does not apply to this Agreement or to any transactions between Buyer and Seller in connection herewith.
27. Submission to Jurisdiction. Any legal suit, action or proceeding arising out of or relating to this Agreement must be instituted in the federal courts of the United States of America or the courts of the State of New York, in each case located in Erie County, New York, and each party irrevocably submits to the exclusive jurisdiction and venue of such courts in any such suit, action or proceeding.
28. Cumulative Remedies. The rights and remedies under this Agreement are cumulative and are in addition to and not in substitution for any other rights and remedies available at law or in equity or otherwise.
29. Notices. All notices, requests, consents, claims, demands, waivers and other communications hereunder (each, a “Notice”) must be in writing and addressed to the parties at the addresses set forth in the first paragraph of these Terms or to such other address that may be designated by the receiving party in writing in accordance with this Section. All Notices must be delivered by personal delivery, internationally recognized overnight courier (with all fees pre-paid) or facsimile (with confirmation of transmission). Except as otherwise provided in this Agreement, a Notice is effective only: (a) upon receipt of the receiving party; and (b) if the party giving the Notice has complied with the requirements of this Section.
30. Severability. If any term or provision of this Agreement is invalid, illegal or unenforceable in any jurisdiction, such invalidity, illegality or unenforceability will not affect any other term or provision of this Agreement or invalidate or render unenforceable such term or provision in any other jurisdiction.
31. Survival. Provisions of these Terms which by their nature should apply beyond their terms will remain in force after any termination or expiration of this Agreement.
32. Amendment and Modification. These Terms may only be amended or modified in a writing stating specifically that it amends these Terms and is signed by an authorized representative of each party. No change to any Purchase Order will binding upon Buyer unless it is in writing, specifically states that it amends the Purchase Order and is signed by an authorized representative of Buyer.
024970.00063 Business 14529773v2
Finding us is as easy as
typing in the little box below